Offer and Acceptance: Southwest Metrics, Inc dba AMCO Enterprises (AMCO) offers to sell and deliver its products and/or services (Goods) in accordance with the terms and conditions set forth in these Standard Terms of Sale (this Contract). Acceptance of any order is expressly limited to the terms of this Contract as they are in effect at the time of acceptance, unless otherwise agreed upon in writing by AMCO and the Buyer (the Parties). AMCO hereby objects to and rejects any additional or different terms proposed by Buyer, including those contained in Buyer's purchase order, unless AMCO expressly agrees to such terms in writing. Prices and Releases: AMCO's price in effect at the time AMCO receives Buyer's purchase order shall continue to apply if the quantity ordered is released by AMCO within twelve (12) months of order acceptance, unless otherwise agreed upon by the Parties in writing. If the price of fuels, metals, raw materials, equipment or other production costs increases significantly, AMCO shall have the right and Buyer shall have the obligation to renegotiate the price of all products not yet shipped, and if an agreement is not reached, AMCO shall have the right to terminate this contract without liability. Title and Delivery: Shipments inside the U.S. shall be delivered F.O.B. AMCO's shipping dock at Fort Fort WorthTX, USA, unless otherwise agreed upon by the Parties in writing. Shipments outside the U.S. shall be delivered via Buyer's designated carrier. Title and liability for loss or damage shall pass to Buyer upon AMCO's delivery to Buyer's designated carrier. Any subsequent loss or damage shall not relieve Buyer from its obligations, including but not limited to those specified in this Contract. Buyer shall reimburse AMCO for insurance and transportation costs on international shipments and shall be responsible for all import duties, taxes and any other expenses incurred or licenses or clearances required, unless otherwise agreed upon by the Parties in writing. AMCO may deliver Goods in installments, and will make every reasonable effort to adhere to Buyer's delivery schedule as specified in writing. However, delivery dates are estimates. AMCO shall not be liable for any damage, losses or expenses incurred by Buyer if AMCO fails to meet the estimated delivery dates. Payment Terms: If AMCO extends credit to Buyer, payment terms shall be net thirty (30) days after AMCO's invoice, unless otherwise specified on the invoice. AMCO reserves the right to refuse credit to any Buyer or prospective Buyer for any reason. AMCO may change or withdraw credit limits or payment terms at any time for any reason. If Buyer fails to make any payment when due, AMCO may suspend or cancel performance under any agreements between AMCO and Buyer. AMCO's suspension of performance may result in rescheduling delays. If, in AMCO's judgment, Buyer's financial condition does not justify the payment terms specified herein or previously agreed upon, then AMCO may terminate this Contract and/or any open order (s) with Buyer unless Buyer immediately pays for all products that have been delivered and pays in advance for all products yet to be delivered. Termination in accordance with this clause shall not affect AMCO's right to pursue any other available remedies. Taxes: Prices do not include applicable taxes or duties. Buyer is solely responsible for paying all applicable taxes and duties. AMCO will add sales taxes to the sales price where required by applicable law, and Buyer will pay such taxes unless Buyer provides AMCO with a duly executed sales tax exemption certificate (more information). Contingencies: AMCO shall not be in breach of any contract and shall not be liable for any non-performance or delay in performance if such non-performance or delay is due to a force majeure event or other circumstances beyond AMCO's reasonable control, including but not limited to, shortages of labor, energy, fuel, machinery or materials, technical or yield

Extra Phones

Phone: 908-241-4179

Fax: 908-241-4179

Hours

Regular Hours

Mon - Fri:	7:00 am - 4:00 pm

Categories

Air Conditioning Contractors & Systems, Air Duct Cleaning, Duct & Duct Fittings, Duct Cleaning, Heating Contractors & Specialties, Major Appliances, Mechanical Contractors

Brands

carrier

Other Link

http://www.amco-enterprises.com

Suggest an Edit

Are You The Business Owner?Claim This Business

Data provided by one or more of the following: Thryv, Data Axle, Yext.

What'sNearby^TM

Amco Enterprise Inc

600 Swenson Dr, Kenilworth, NJ 07033

PHOTOS AND VIDEOS

Quality Air Conditioning & Heating Inc

A1 Electric, Heating and Air Conditioning

REVIEWS Write a Review